Employers beware of delay-related risk
The English Court of Appeal recently handed down its judgment in Telford Homes (Creekside) Ltd v Ampurius Nu Homes Holdings Ltd, overruling the High Court decision that the employer had been entitled to terminate a construction contract on the grounds that the contractor’s extensive delay in performing the works amounted to a repudiatory breach of the agreement. The decision confirms that it will only be in exceptional cases that delay in construction contracts will amount to repudiation, thereby giving the other party the right to terminate the contract.
A construction company, Telford Homes, was contracted by Ampurius Nu Homes Holdings to construct four blocks (tiled ‘A’, ‘B’, ‘C’ and ‘D’) for a 999-year lease for a consideration of £8m. During the course of the contract, Telford experienced financial difficulties and stopped work on blocks A and B, but it continued work on blocks C and D. Almost a year after work was halted on blocks A and B, Telford recommenced the work on these two blocks. This was seemingly unbeknown to Ampurius, although Telford had suggested that it would recommence work when it had organised further financing.
Shortly thereafter, Ampurius informed Telford that it had terminated the contract. The main ground for termination was that the continued works on blocks A and B potentially interfered with the marketing of blocks C and D, which were nearing completion…
If you are registered and logged in to the site, click on the link below to read the rest of the King & Wood Mallesons briefing. If not, please register or sign in with your details below.
News from King & Wood Mallesons
News from The Lawyer
Briefings from King & Wood Mallesons
High Court decides: liquidators of insolvent landlords can disclaim leases with the effect of extinguishing the tenant’s leasehold interest
In Willmott Growers Group Inc v Willmott Forests Limited, the majority of the High Court upheld the Victorian Court of Appeal’s conclusion that the liquidators of an insolvent landlord can disclaim a lease.
Queensland recently brought an interlocutory application seeking a declaration that its laws were valid until a court finally determined otherwise.
Analysis from The Lawyer
All-encompassing change is now a reality for the UK’s top 200 firms. How are they coping with the unprecedented upheaval? The Lawyer finds out